HomeMy WebLinkAboutReso - CC - 035-1948RESOLUTION NO. 35-48
AUTHORIZING EXECUTION OF CONTRACT
IffITH ARCHITECT FOR ERECTION Or A
DRILL TOW.'.�,R AND FIRE STATION.
1.4HEREAS, the City Council of the City of Burlingame
have employed Leo J. Sharps and Irving F. Brovm, Architects
Associated, for architectural and professional services in
connection with the construction of a Drill mower and Fire
Station to be located within the City of Burlingame; and
WHEREAS, there is attached hereto the agreement to be
entered into between the architects and the city employing, them
for the work to be performed and according to the terms therein
stated;
NOW, THEREFORE, BE IT RESOLVED, that the City of Burlingame
be, and through the City Council enter into an Agreement with
Leo J. Sharps and Irving F. Brown, Architects Associated, for
their architectural and professional services in connection with
the construction of a Drill Tower and Fire Station for the Fire
Department to be located within the City of Burlingame, all as set
-forth and according to the terms of the attached agreement;
BE IT FURTHER RESOLVED that the Mayor and he is hereby
authorized to execute the aforesaid contract for and in behalf
of the City of Burlingame.
U. S. Simonds, Jr., - !layor
I, Herbert K. White, City Clerk, do hereby certify that
the foregoing resolution was regularly introduced and adopted by
the City Council on August 16, 1946, by the following vote:
AYES: COUNCIL11EA:
NOES: COUNCILPIEN: NO
ABSENT COUdCIMIEN:
Herbert. _ite, 4CI
RESOLUTION NO. 35-48
AUTHORIZING EXECUTION OF CONTRACT
SITH ARCHITECT FOR ERECTION OF A
'DRILL TOVII:,R AND FIRE STATION.
?:MREAS, the City Council of the City of Burlingame
have employed Leo J. Sharps and Irvin.- F. Brown, Architects
Associated, for architectural and professional services in
connection with the construction of a Drill Tower and Fire
Station to be located within the City of Burlingame; and
WHEREAS, there is rttached hereto the agreement to be
entered into between the architects and the city employing them
for the work to be performed and according to the terms therein
stated;
NOW, THEREFORE, BE IT RESOLVED, that the City of Burlingame
be, and throu,h the City Council enter into an Agreement with
Leo J. Sharps and Irvin;; F, Brown, Architects Associated, for
their architectural and professional services in connection with
the construction of a Drill Tower and Fire Station for the Fire
Department to be located within the City of Burlingame, all as sett
forth and according to the terms of the attached agreement;
BE IT FURTHER RESOLVED that the Mayor and he is hereby
authorized to execute the aforesaid contract for and in behalf
of the City of Burlingame.
i
_A�
• ua.auviturs, Ji'., — j4jayor
I, Herbert K. White, City Clerk, do hereby certify that V
the foregoing resolution was re;ularly introduced and adopted by
the City Council on Au ust 16, 194B9 by the following Note:
r1IT's:
COUNCILMEN:
DAHL-iURPER-IIMTT-LOVE-SIMOIOS
NOES:
COUNCILMEN:
NONE
ABSENT
COUNCILMEN:
NONE
Her er, t.ii e, - City`C er
AGREEMENT FOR ARCHITECTURAL SERVICES
THIS AGREEMXNT made in duplicate in the City of
Burlingame, County of San Mateo, State of California,
1948, by and between the CITY OF BURLINGAME, hereinafter called
"City" and LEO J, SHARPS and IRVING F. BROWN, co-partners doing
business under the firm name of SHARPS and BROWN, architects, of
Burlingame, San Mateo County, California, hereinafter called
"Architect".
GENERAL SCOPE OF EMPLOYMENT,
The City hereby employs the Architect to prepare
detailed working drawings and specifications for and, the super-
vision of the construction of a FIRE DRITLL TOWER to be located
at the Headquarters Station of the Burlingame Fire Department
and for a new FIRE STATION to be located 1n the northern part of
the City of Burlingame.
NOW, THEREFORE, IT IS HERBY AGREED AS FOLLOWS:
1, WORK To BE PERFORMED, Architect shall perform for
the above -named City, the *pork and professional services as here-
inafter set forth,
2, PAYMENT OF ARCHITECT'S FEES, City shall pay architect
for such services a fee of eight g per cent (8%) of the cost of all
work, with other payments and reimbursements
the said percentages bein h as hereinafter provided,
g hereinafter referred to as the "Basic
rate", From such fee shall be
is heretofore deducted the sum of $500o00y which
$ of August as having been paid architect under said
agreement gust �7
, 1946,
3. ARCHITECT'S SMICES. Architect's professional
services consist of the necessary conferences, the preparation
of preliminary studies, working drawin.gy, sptici ica inns, lurg�
scale and full e;ize) detcil carat - Ags; this draftlnr ; cf fcsrue o:
propf;saly and cetitzact-,; the isec>rnce of certificates of paymer('�;
the L-eepSin c;_ acc()urte, th;; general 4dW�•!rl=rt 'e,t�se•n of the
%Voineea ArC3 SL+per'?_s_Ctj cf the I!crk,
4. TCTRA 02TVI.0 S ND SPEC=A_?: Ci>SFS. I; uz•ct:ltec- ie
cauaF%, e:-trf( or othe.: fiix finoe eue to chpr.g•es ordered by
City, or due to the delinquency or insolvency of tt_e Ci0,71 Cr,
contractor, Or ac a. reedt cf dttmage by :ire, tb!ey zhall Le
equitably gain for r.uel; extra expense, and the service involved.
If any work decetgrcd or specizled by architect iu
abandoned or suspended architect is to be praild for the servioec
rendered on account of it,
b. PAYMENTS Of! ACCOUNT. Paymente to architect, on
account of his fee eha.11 be made! ae folloae, subject to the pro-
vicion(; of paragraphs n, 3, 4 er_e ? hereof:
Upon oamT>2etion of opeeifi.catione Lnd Evnerat, working
drawings (exclusive of details) a sum equal to 75% of the rate
or rates of commis(aion arising from this agreement, computed -
upon a reasonable cost estimates. on such completed epeoifioati.etts
and: dr•awinEe, or if b1de 1mve been rece_ved, then computed upon
the ioweet bona fine bid or bide.
From time to time during the exe:cuti_n of the work, Eald.
In proportion to the amount of serv,ee rendered by the architect
Payments ehali be made until the aggregate of all payments made
on account of the fee under this paragraph shall be a sum equal
to the rate or rates of commission arising from this agreement,
computed upon the final cost of the work.
No deductions shall be made from architect's fee on
account of penalty, liquidated damages, or other sums witheld from
payments to contractors.
6. SURVEY, BOR114GS IUM TESTS. City shall, so far as
the work under this agreement may require, furnish the architect
with the following information: A complete and accurate survey
of the building sites, giving the grades and lines of streets,
pavements, and adjoining prop--rties; the rights, restrictions,
easements, boundaries, and contours of the building sites, and
full information as to sewer, water, gas and electrical service.
7. SUPERVIS_;ON OF THE WORK. Architect will endeavor
to guard City against :iefects and deficiencies in the work of con-
tractors, but he does not guaranty the performance of their con-
tracts. The supervisie:n of architect is to be distinguished from
the continuous persons I. superintendence to be obtained by the em-
ployment of a clerk-ol'-the---works.
When authorizes; by City, a clerk -of -the -works acceptable
to both city and architect shall be engaged by architect at a
salary satisfactory to tr,e city and paid by city, upon presentation
of architect's monthly statements,
8. PRELIMINAR.' ESTIMATES
When requested to do so the
architect will furnish preliminary estimates on the cost of the
work, but he does not gu&,.antee the accuracy of such estimates.
9, DEFINITION C _7.'HE COST Of THE WORK. The cost of ti,e
work, as herein referred tit, rncans the cost to city, but such cost
shall not include any archI_tec.v,.3 or engineer's fees or reimburse-
ments of the cost ox a cleric -of -the -works.
When labo.- or material. is furnished by city below its
market cost, the cost of the fora, shall be computed upon such
market cost.
10. OWNERSHIP OF DOCUMENTS. Drawings and specifi-
cations as instruments of service are the property of architect,
except as otherwise provided, whether the woriv. for which they
are made be executed or not.
11. SUCCESSORS AND ASSIGNS. Architect binds himself,
his successors, executors, administrators, and assigns, to city
in respect Of .all covenants of this agreement.
Except as above, neither the city nor the architect
shall assign, sublet or transfer his or its interest in this
agreement without the written consent of the other party.
3.2. PMITRATION. In the event that any dispute shall
have arisen between City and Architect as to any matter contained
In this agreement, architect shall choose one person as arbitrator,
city shall choose one person as arbitrator, and such two arbitrators
shall choose a third person as arbitrator. Such three persons shall
constitute a board of arbitration, and the decision of two out of
three of such persons shall be final and binding upon the parties
hereto.
IN WITNESS WHEREOF, the city has hereunto set its
hand and affixed its official seal by and through its officers
duly authorized thereunto, and the architect has hereunto set
his hand the day and year first hereinabove written.
CITY OF BURLINGA_ ME
-City of Burl2ngame -___. -�
Mayor -
Are .eot
-rchitect