Loading...
HomeMy WebLinkAboutReso - CC - 045-2014RESOLUTION NO. 45-2014 RESOLUTION OF THE CITY COUNCIL OF THE CITY OF BURLINGAME APPROVING AND AUTHORIZING THE MAYOR TO EXECUTE AN AMENDMENT TO THE AGREEMENT WITH CAINE COMPUTER CONSULTING, LLC TO PROVIDE INFORMATION TECHNOLOGY SERVICES TO THE CITY'S POLICE DEPARTMENT WHEREAS, in May of 2008, the City Council approved an agreement with Caine Computer Consulting, LLC to provide information technology management services to the City's Police Department and in June of 2010, and June of 2013 the City Council approved a renewal of said agreement; and WHEREAS, the City's Police Department, having benefited greatly from the services provided by Caine Computer Consulting, desires to renew the agreement with Caine Computer Consulting for the provision of information technology management services; and WHEREAS, Caine Computer Consulting is willing and able to continue to provide such information technology management services; NOW, THEREFORE, THE CITY COUNCIL OF THE CITY OF BURLINGAME RESOLVES AND ORDERS AS FOLLOWS: The City Council approves and authorizes the Mayor to execute a renewed agreement with Caine Computer Consulting, LLC, in the form attached hereto as Exhibit "A" which is incorporated herein by this reference. Michael Brownrrgg) Mayor I, Mary Ellen Kearney, City Clerk of the City of Burlingame, do hereby certify tl�at the foregoing Resolution was introduced at a regular meeting of the City Council held on the 2nd day of June, 2014 and was adopted thereafter by the following vote: AYES: COUNCILMEMBERS: BROWNRIGG, DEAL, KEIGHRAN, NAGEL, ORTIZ NOES: COU NCI LM EMBERS: NONE ABSENT: COUNCILMEMBERS:NONE qh�llG L" Mary Elle4 Kearney, City Clerk Ecce-313IWelf1t i;3u3l]aI331cI1`MILIA WANO &I This Agreement for Professional Services (the "Agreement"), effective May 1, 2008, is by and between The City of Burlingame, with its principal office in Burlingame, California (hereinafter "Client"), and Caine Computer Consulting, LLC, corporation, with its principal office in Redwood City, California, (hereinafter the "Company") WHEREAS, Client finds that the Company is willing to perform certain work hereinafter described in accordance with the provisions of this Agreement; and WHEREAS, Client finds that the Company is qualified to perform the work, all relevant factors considered, and that such performance will be in furtherance of Client's business. WHEREAS, Company will provides services both onsite and remotely at Company's place of business as the need arises. NOW, THEREFORE, in consideration of the mutual covenants set forth herein and intending to be legally bound, the parties hereto agree as follows: 1. SERVICES. 1.1 Effective Date and Term. This Agreement is effective as of July 1, 2014. The term of this agreement is from the Effective Date until June 30, 2015. Services to Client. The Company shall provide the following ("Services") to Client: Network/ Computer System Administration Website Administration Project Management Computer Software Management, including but not limited to, the Hitech Systems software, Sunridge Systems software Email System Management Telephone System Management Training and Computer Education to employees City Projects as needed New Projects and responsibilities can be added to the above list if mutually agreed upon by the parties. Company agrees to provide consulting services, such as discussing available options, troubleshooting, recommending solutions and working with employee and equipment vendors as needed. Client will be responsible for all hardware components. If hardware repair and support is needed, Client agrees to pay for contractor parts and services. Cabling will be performed by cabling contractors approved jointly by Client and Company and paid for by Client. Company will work with the equipment vendors to troubleshoot issues and replace components under warranty. Any purchases made will conform to Client's purchasing policies and procedures. Company will provide support for workstation software, including the initial installation, . re -installation, software upgrades/patches and configuration changes, requested by Client. Company support for service software includes the initial installation, re -installation, software upgrades/patches and on-going monitoring of system processes which include daily backup, logs, alarms and alerts. Software loaded on servers and workstations must be approved by Company. Client will pay for any technical support contracts for third -party software. Company employee(s) will report directly to the Administrative Commander, a Police Department employee, or his/her designee. Company agrees to keep the Administrative Commander or his/her designee informed of work performed, and upon request, will provide an accounting of work done on projects. Client will be responsible for purchasing and upgrading software licenses. Company will provide services both on site and remotely in order to maintain the integrity of the Clients computer systems. If a significant amount of work is required to be done after normal business hours (0800-1700) due to an emergency or other after-hours need, that work may be invoiced in addition to the contract amount, at a rate $58.11 per hour or another amount which has been mutually agreed upon by both parties. If both parties agree, normal business hours can be adjusted to meet the needs of both. Company agrees to be available 24 hours a day, 7 days a week by providing home telephone, business telephone and cellular telephone numbers unless notice has been given otherwise to Client. If Company will not be available, Company will provide a list of alternative support options for Client to call in the event of emergency. 2. PAYMENT AND INVOICING TERMS. 2.1 Payment for Services. The Company will be paid as follows: $122,756.13 annually to be paid monthly at the rate of $10,229.67 per month. 0 Additional payment for specific projects may be negotiated separately and payment may be by hour or by project as mutually agreed upon. 2.2 Reimbursable Costs. Client shall reimburse the Company all costs incurred in connection with the Services rendered. Reimbursable costs include, but are not limited to, travel costs, subcontractors, materials and computer costs, copies, delivery, etc. that are attributable to a project or Service (the "Reimbursable Costs"). Travel costs are defined as air travel, lodging, meals and incidentals, ground transportation, tools, and all costs associated with travel. All travel expenses. must receive Client's approval. The Company shall provide to Client substantiation of Reimbursable Costs incurred. Client will provide all equipment and software necessary for the fulfillment of this contract, at no cost to Company. 2.3 Invoicing. (a) Invoices will submitted monthly by the Company for payment by Client. Payment is due upon receipt and is past due seven (30) business days from receipt of invoice. If Client has any valid reason for disputing any portion of an invoice, Client will so notify the Company within seven (7) calendar days of receipt of invoice by Client, and if no such notification is given, the invoice will be deemed valid. The portion of the Company's invoice that is not in dispute shall be paid in accordance with the procedures set forth herein. Any attorney fees, court costs, or other costs incurred in collection of delinquent accounts shall be paid by Client. If payment of invoices is not current, the Company may suspend performing further work. 3. CHANGES. Client may, with the approval of the Company, issue written directions within the general scope of any Services to be ordered. Such changes (the "Change Order") may be for additional work or the Company may be directed to change the direction of the work covered by the Task Order, but no change will be allowed unless agreed to by the Company in writing. 4. STANDARD OF CARE. The Company warrants that it services shall be performed by personnel possessing competency consistent with applicable industry standards. No other representation, express or implied, and no warranty or guarantee are included or intended in this Agreement, or in any report, opinion, deliverable, work product, document or otherwise. Furthermore, no guarantee is made as to the efficacy or value of any services performed or software developed. This Section sets forth the only warranties provided by the company concerning the services and related work product. This warranty is made expressly in lieu of all other warranties, express or implied, including without limitation any implied warranties of fitness for a particular purpose, merchantability, non -infringement, title or otherwise. 5. LIABILITY. 5.1 Limitation. Company will provide a Liability and Errors and Omissions insurance policy in the amount of $1,000,000. The Company's liability, including but not limited to Client's claims of contributions and indemnification related to third party claims arising out of services rendered by the Company, and for any losses, injury or damages to persons or properties or work performed arising out of or in connection 3 with this Agreement and for any other claim, shall be limited to the amount of the policy. Notwithstanding anything to the contrary in Us Agreement, the Company shall not be liable for any special, indirect, consequential, lost profits, or punitive damages. Client agrees to limit the Company's liability to Client and any other third party for any damage on account of any error, omission or negligence to a sum not to exceed the amount of the insurance policy. The limitation of liability set forth herein is for any and all matters for which the Company may otherwise have liability arising out of or in connection with this Agreement, whether the claim arises in contract, tort, statute, or otherwise. 5.2 Survival. Articles 2, 4, 5, and 6 survive the expiration or termination of this Agreement for any reason. 6. MISCELLANEOUS. Company may consult with other Vendors as needed and Client agrees to pay the costs thereof. All expenditures will be agreed upon before such consultation is sought. 6.1 Insecurity and Ade uate Assurances. If reasonable grounds for insecurity arise with respect to Client's ability to pay for the Services in a timely fashion, the Company may demand in writing adequate assurances of Client's ability to meet its payment obligations under this Agreement. Unless Client provides the assurances in a reasonable time and manner acceptable to the Company, in addition to any other rights and remedies available, Company may partially or totally suspend its performance while awaiting assurances, without any liability. 6.2 Severability. Should any part of this Agreement for any reason be declared invalid, such decision shall not affect the validity of any remaining provisions, which remaining provisions shall remain in full force and effect as if this Agreement had been executed with the invalid portion thereof eliminated, and it is hereby declared the intention of the parties that they would have executed the remaining portion of this Agreement without including any such part, parts, or portions which may, for any reason, be hereafter declared invalid. Any provision shall nevertheless remain in full force and effect in all other circumstances. 6.3 Modification and Waiver. Waiver of breach of this Agreement by either part shall not be considered a waiver of any other subsequent breach. 6.4 Pension Reform Act of 2013 Company shall be responsible for compliance with relevant law, including, to the degree it may be applicable, the Public Employees Pension Reform Act of 2013 [PEPRA]. Company shall report with its regular invoices on any hours worked by an employee that may be subject to limitation under PEPRA. 6.5 Independent Contractor. The Company is an independent contractor of Client. 6.6 Notices. Client shall give the Company written notice within one hundred eighty (180) days of obtaining knowledge of the occurrence of any claim or cause of action which Client believes that it has, or may seek to assert or allege, against the Company, whether such claim is based in law or equity, arising under or related to this Agreement or to the transactions contemplated hereby, or any act or omission to act by the Company with respect hereto. If Client fails to give such notice to the Company with regard to any such claim or cause of action and shall not have brought legal action for such claim or cause of action within said time period, Client shall be deemed to have waived, and shall be forever barred from bringing or asserting such claim or cause of action in any suit, action or proceeding in any court or 4 before any governmental agency or authority or any arbitrator. All notices or other communications hereunder shall be in writing, sent by courier or the fastest possible means, provided that recipient receives a manually signed copy and the transmission method is scheduled to deliver within 48 hours, and shall be deemed given when delivered to the address specified below or such other address as may be specified in a written notice in accordance with this Section. Any party may, by notice given in accordance with this Section to the other parties, designate another address or person or entity for receipt of notices hereunder. 6.7 Assignment. The Agreement is not assignable or transferable by Client. This Agreement is not assignable or transferable by the Company without the written consent of Client, which consent shall not be unreasonably withheld or delayed. 6.8 Disputes,. The Company and Client recognize that disputes arising under this Agreement are best resolved at the working level by the parties directly involved. Both parties are encouraged to be imaginative in designing mechanism and procedures to resolve disputes at this level. Such efforts shall include the referral of any remaining issues in dispute to higher authority within each participating party's organization for resolution. Failing resolution of conflicts at the organizational level, the Company and Client agree that any remaining conflicts arising out of or relating to this Contract shall be submitted to nonbinding mediation unless the Company and Client mutually agree otherwise. If the dispute is not resolved through non-binding mediation, then the parties may take other appropriate action subject to the other terms of this Agreement. 6.9 Section Headings. Title and headings of sections of this Agreement are for convenience of reference only and shall not affect the construction of any provision of this Agreement. 6.10 Representations; Counterparts. Each person executing this Agreement on behalf of a party hereto represents and warrants that such person is duly and validly authorized to do so on behalf of such party, with full right and authority to execute this Agreement and to bind such party with respect to all of its obligations hereunder. This Agreement may be executed (by original or telecopied signature) in counterparts, each of which shall be deemed an original, but all of which taken together shall constitute but one and the same instrument. 6.11 Residuals. Nothing in this Agreement or elsewhere will prohibit or limit the Company's ownership and use of ideas, concepts, know-how, methods, models, data, techniques, skill knowledge and experience that were used, developed or gained in connection with this Agreement. The Company and Client shall each have the right to use all data collected or generated under this Agreement. 6.12 Cooperation. Client will cooperate with the Company in taking actions and executing documents, as appropriate, to achieve the objectives of this Agreement. Client agrees that the Company's performance is dependent on Client's timely and effective cooperation with the Company. Accordingly, Client acknowledges that any delay by Client may result in the Company being released from an obligation or scheduled deadline or in Client having to pay extra fees for the Company's agreement to meet a specific obligation or deadline despite the delay. 6.13 Goveuning Law and Construction. This Agreement will be governed by and construed in accordance with the laws of 5 California, without regard to the principles of conflicts of law. The language of this Agreement shall be deemed to be the result of negotiation among the parties and their respective counsel and shall not be construed strictly for or against any party. 6.14 Arbitration. Any controversy, dispute or claim arising out of or related to this Agreement or breach of this Agreement shall be settled solely by confidential binding arbitration by a single arbitrator in accordance with the commercial arbitration rules of JAMS in effect at the time the arbitration commences. The award of the arbitrator shall be final and binding. No party shall be entitled to, and the arbitrator is not authorized to, award legal fees, expert witness fees, or related costs of a party. The arbitration shall be held in 6.15 Termination of Contract. This contract may be terminated upon written notice delivered by either Client or Company not less than Ninety (90) days prior to the termination date. 6.16 Entire Agreement; Survival. This Agreement, including any Exhibits, states the entire Agreement between the parties and supersedes all previous contracts, proposals, oral or written, and all other communications between the parties respecting the subject matter hereof, and supersedes any and all prior understandings, representations, warranties, agreements or contracts (whether oral or written) between Client and the Company respecting the subject matter hereof. This Agreement may only be amended by an agreement in writing executed by the parties hereto. This agreement will remain in force for one year from the date of signing and can be renewed under mutual agreement of both parties. 6.17 Force. Majeure. The Company shall not be responsible for delays or failures (including any delay by the Company to make progress in the prosecution of any Services) if such delay arises out of causes beyond its control. Such causes may include, but are not restricted to, acts of God or of the public enemy, fires, floods, epidemics, riots, quarantine restrictions, strikes, freight embargoes, earthquakes, electrical outages, computer or communications failures, and severe weather, and acts or omissions of subcontractors or third parties. 6.18 Use By Third Parties. Work performed by the Company pursuant to this Agreement is only for the purpose intended and may be misleading if used in another context. Client agrees not to use any documents produced under this Agreement for anything other than the intended purpose without the Company's written permission. This Agreement shall, therefore, not create any rights or benefits to parties other than to Client and the Company. IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the day and year first above written. Date: 6-2 — /' f City of Burlingame By Title: Caine Computer Consulting, LLC By: ic"" , l I + l t �C Q /� `(/�� Title: 6u);q e_l— i